������Ƶ

1. Parties: Identification of the Principal/Owner and the Construction Manager, including their legal details and representatives

2. Background: Context of the project, purpose of the agreement, and brief description of the construction works

3. Definitions: Definitions of key terms used throughout the contract

4. Appointment and Scope of Services: Formal appointment of the Construction Manager and detailed scope of construction management services

5. Construction Manager's Obligations: Core responsibilities including project management, coordination, scheduling, cost control, and quality assurance

6. Principal's Obligations: Owner's responsibilities including provision of information, approvals, and payment obligations

7. Project Timeline: Key milestone dates, project schedule, and completion requirements

8. Compensation and Payment: Fee structure, payment terms, and invoicing procedures

9. Changes and Variations: Process for managing changes to scope, timeline, or costs

10. Quality Management: Quality standards, inspection requirements, and quality control procedures

11. Health, Safety and Environment: HSE requirements and compliance with Indonesian regulations

12. Subcontracting: Rules and procedures for engaging and managing subcontractors

13. Insurance and Indemnity: Required insurance coverage and indemnification obligations

14. Intellectual Property: Ownership and usage rights of project documentation and designs

15. Confidentiality: Protection of confidential information and trade secrets

16. Term and Termination: Contract duration, renewal terms, and termination provisions

17. Dispute Resolution: Dispute resolution procedures including mediation and arbitration requirements

18. Governing Law: Confirmation of Indonesian law as governing law and jurisdiction

19. General Provisions: Standard boilerplate clauses including notices, assignment, and severability

1. Schedule 1 - Scope of Services: Detailed description of construction management services

2. Schedule 2 - Fee Schedule: Detailed breakdown of fees, rates, and payment milestones

3. Schedule 3 - Project Program: Detailed project timeline, milestones, and critical path

4. Schedule 4 - Key Personnel: List of key personnel and their roles/responsibilities

5. Schedule 5 - Site Information: Site details, access requirements, and existing conditions

6. Schedule 6 - Forms and Procedures: Standard forms for variations, claims, and reports

7. Schedule 7 - Quality Management Plan: Detailed quality management procedures and requirements

8. Schedule 8 - HSE Requirements: Detailed health, safety, and environmental requirements

9. Appendix A - Project Drawings: Reference drawings and specifications

10. Appendix B - Permits and Approvals: List of required permits and responsible parties